Financial- Staton Construction - Laserfiche WebLink

Home Browse Search

SALEM COURTHOUSE SQUAR NC. Demolition `" 1997 SECTION 00900 ~ GENERAL CONDTI'IONS PAGE 5 OF 6 reason of the failure of the CONTRACTOR or any of his subcontractors to comply with such law, orders, rules, regulations or ordinances. CONTRACTOR shall obtain all permits required for execution of specified work and shall pay all fees thus entailed. 919 PAYMENT: The CONTRACTOR shall apply for payment under this contract by completing AIA Form G702, "Application and Certificate for Payment" to Marion County, attention Randy Curtis, Department of General Services, 100 High St. NE Salem, Oregon, 97301. No "Past Due" amount shall be payable until thirty (30) days from the date an approved application for payment is received by the OWNER. 920 RETAINAGE: A sum equal to five percent (5%) of the cumulative total amounts due shall be retained by OWNER from payments, for a period of thirty (30) days after final acceptance of work, to satisfy any lien resulting from performance of this Agreement. 921 CONTRACTOR REGISTRATION AND LICENSING: The CONTRACTOR shall provide written evidence to the OWNER proving that the CONTRACTOR is registered or licensed as may be required by the laws of Oregon State, ORS 468.883. 922 RIGHT OF OWNER TO DO WORK: Should the CONTRACTOR neglect to prosecute the work properly or fail to perform any provision of the Agreement, the OWNER may, twenty-four (24) hours after the delivery of written notice to the CONTRACTOR, and without prejudice to any other remedy OWNER may have, make good such deficiencies and may deduct the cost thereof from any payment then or thereafter due the CONTRACTOR. 923 TERMINATION FOR DEFAULT: Should the CONTRACTOR, in the OWNER's judgment, neglect to pursue the work or otherwise fail to perform any provision of the AGREEMENT, the OWNER may within twenty-four (24) hours of delivery of written notice to CONTRACTOR, terminate the employment of the CONTRACTOR and take possession of the premises and of all materials thereon and ~nish the work by whatever method OWNER shall deem expedient. In such case, CONTRACTOR shall not be entitled to receive any further payment until work is finished and costs are determined. If the unpaid balance of the contract price exceeds the expense of finishing the work, including compensation for additional management and administration services, such excess shall be paid to the CONTRACTOR. If such cost to complete the work exceeds such unpaid balance, the CONTRACTOR shall pay the difference to the OWNER. 924 NOTICE OF INTERFERENCE: In the event the CONTRACTOR feels that the CONTRACTOR's performance of the Contract has been delayed or interfered with by any act of the OWNER, CONTRACTOR agrees to tender the OWNER written notice thereof within three (3) days of the date of such occurrence. CONTRACTOR shall not be entitled to any additional compensation for such occurrence unless the notice is tendered within three days of the date of the occurrence. 925 DIFFERING CONDITIONS: a) The CONTRACTOR shall promptly, and before such conditions are disturbed, notify the OWNER in writing of: 1) latent physical conditions at the site differing materially from those indicated in this contract, or, 2) unknown physical conditions at the site, of an unusual nature differing materially from those ordinarily encountered and general recognized as inhering in work of the character provided for in